Terms of Service

Welcome to Parry Construction. These Terms of Service ("Terms") govern your use of our website, services, and any construction projects undertaken by our company. By accessing our website or engaging our construction services in Los Angeles, you agree to be bound by these Terms.

Parry Construction is a licensed general contractor serving the Los Angeles area. These Terms outline the legal relationship between you and our company regarding website usage, service inquiries, project engagements, and related communications.

Last Updated: November 4, 2025

By accessing our website, submitting project inquiries, or engaging Parry Construction for construction services, you acknowledge that you have read, understood, and agree to be bound by these Terms of Service. If you do not agree to these Terms, you should not use our website or services.

These Terms constitute a legally binding agreement between you and Parry Construction. We reserve the right to modify these Terms at any time, and your continued use of our services constitutes acceptance of any changes.

Parry Construction provides professional construction services including but not limited to residential construction, commercial projects, renovations, remodeling, and design-build solutions throughout Los Angeles and surrounding areas.

As a client of Parry Construction, you have certain responsibilities to ensure successful project completion and maintain a professional working relationship:

Payment terms for construction services are outlined in project-specific contracts and agreements. Standard payment practices include:

• Initial deposit upon contract signing (typically 10-20% of project value)
• Progress payments based on completed milestones
• Final payment upon substantial completion and client approval
• Retainage may be held for warranty period as specified in contract
• All payments are due within specified timeframes as outlined in invoices

Late payments may be subject to interest charges and may impact project timelines. Payment terms are subject to change based on project scope and client requirements.

Changes to project scope, design, or specifications must be documented through formal change orders. This process ensures clarity and proper documentation of all modifications:

• All change requests must be submitted in writing
• Parry Construction will provide cost and timeline impact assessments
• Change orders require client approval before implementation
• Additional costs and timeline adjustments will be clearly documented
• Verbal agreements for changes are not binding without written confirmation

This process protects both parties by ensuring all changes are properly documented, priced, and approved before work begins.

Parry Construction stands behind our workmanship and materials. Standard warranty provisions include:

To the fullest extent permitted by law, Parry Construction's liability is limited as follows:

• Total liability shall not exceed the contract value for the specific project
• We are not liable for consequential, indirect, or punitive damages
• Liability is limited to direct damages resulting from our negligence or breach of contract
• We are not responsible for delays caused by factors beyond our control
• Client assumes responsibility for maintaining appropriate insurance coverage

These limitations are designed to allocate risks fairly between parties while maintaining our commitment to quality construction and client satisfaction.

Either party may terminate construction services under the following conditions:

• Termination for cause with written notice and opportunity to cure
• Termination for convenience by client with payment for work completed
• Termination for material breach of contract terms
• Termination due to circumstances beyond either party's control

Upon termination, clients are responsible for payment for all work completed and materials procured up to the termination date. Final settlement will be calculated according to contract terms and documented change orders.

Parry Construction is committed to resolving disputes amicably and efficiently. Our dispute resolution process includes:

• Direct negotiation between parties to reach mutually acceptable solutions
• Mediation through neutral third-party mediators if direct negotiation fails
• Binding arbitration as required by California contractor licensing requirements
• All disputes governed by California law and Los Angeles County jurisdiction

This approach minimizes legal costs while ensuring fair resolution of any disagreements that may arise during construction projects.

Your use of our website is subject to the following terms:

• Website content is for informational purposes only
• Do not use automated tools to scrape or harvest website data
• Respect all copyright and intellectual property rights
• Do not attempt to compromise website security or functionality
• Project galleries showcase our work but do not guarantee specific results

We reserve the right to modify website content, features, and availability at any time without notice. Website usage does not create a contractual relationship until a formal agreement is executed.

All content on our website, including text, images, designs, and technical information, is the intellectual property of Parry Construction or our content suppliers and is protected by copyright and other intellectual property laws.

Project designs, plans, and specifications created for clients remain the intellectual property of Parry Construction until full payment is received, at which point rights transfer as specified in project agreements.

You may not reproduce, distribute, or create derivative works from our website content without explicit written permission from Parry Construction.

Parry Construction maintains comprehensive insurance coverage including:

• General liability insurance with $2,000,000 coverage
• Workers' compensation insurance as required by California law
• Automotive liability insurance for company vehicles
• Builder's risk insurance for projects in progress

Clients agree to indemnify Parry Construction against claims arising from client negligence, failure to maintain property insurance, or breaches of client responsibilities under these Terms.

Parry Construction is not liable for delays or failures to perform obligations due to circumstances beyond our reasonable control, including but not limited to:

• Natural disasters, severe weather, or acts of God
• Labor disputes, strikes, or workforce shortages
• Material shortages or supply chain disruptions
• Government actions, permit delays, or regulatory changes
• Utility outages or infrastructure failures

In such events, we will make reasonable efforts to mitigate impacts and resume performance as soon as practicable. Project timelines may be adjusted accordingly.

These Terms of Service and any disputes arising from our services or website usage are governed by the laws of the State of California and the United States of America.

Any legal proceedings shall be conducted in Los Angeles County, California, and you consent to the exclusive jurisdiction of California state and federal courts.

These Terms comply with California Contractor License Board requirements and all applicable state and federal regulations governing construction services.

Parry Construction may update these Terms of Service periodically to reflect changes in our business practices, legal requirements, or service offerings. We will notify you of significant changes by:

• Posting updated Terms on our website with effective date
• Emailing clients about material changes to service terms
• Providing notice during project consultations for significant changes

Your continued use of our website or services after changes constitutes acceptance of the updated Terms. Questions about changes should be directed to our contact information below.

If you have questions about these Terms of Service or need clarification regarding any provisions, please contact us using the information below:

For legal inquiries regarding these Terms, please include "Terms of Service" in your email subject line. We will respond to your inquiry promptly and provide any necessary clarification.